Shopping Cart (0) items Sign In

Construction Claims Monthly - Devoted exclusively to the problems of construction contracting since 1963

‹ Prev article: 

'ACT OF GOD,' Not Differing Conditions, Delayed Work and Increased Costs

Tuesday, January 08, 2019 02:44 pm


Differing Site Conditions

Appeal of: Tidewater, Inc., 2018 ASBCA Lexis 308 (November 2, 2018)

A contractor failed to convince the Armed Services Board of Contract Appeals that above-average rain and overly saturated soil amounted to differing site conditions for which it could recover damages. 

In September 2012, the U.S. Army Corps of Engineers (Corps) awarded Tidewater, Inc. (Tidewater) a task order (as part of a multiple award, indefinite-delivery, indefinite-quantity contract) to renovate a building at Barksdale Air Force Base in Louisiana and "create a complete and usable facility" for a dental facility. The Corps estimated the project was worth more than $5 million. The project performance period was 730 calendar days. 

In June 2015, Tidewater gave notice of differing site conditions (DSC), stating that "the soil conditions when it sought to install piers, and obtain fill, for a building addition differed materially from those indicated in contract documents due to excessive rainfall, forcing it to change its construction method and incur additional performance time." 

Tidewater submitted a certified claim seeking $726,669 in damages and a time extension of 215 additional calendar days due to weather and Type I DSC. 

In addition, Tidewater claimed that it was delayed 40 days because it was unable to obtain the required fill due to wet conditions.

The contracting officer (CO) denied the claim, alleging that Tidewater failed to demonstrate essential element [...]

› Next article: 
Sign up now for Construction Claims Monthly Online! Your own virtual help desk of must-have techniques, tutorials, and how-to articles.
Join Now Construction Claims Monthly! Close

Dear Valued Customers,

We regret to announce that ProEdTech LLC and all its affiliate brands will cease operations on April 1, 2019.

We are no longer able to fulfill online orders. We will fullfill all DVD and book orders already placed.

Customers of canceled webinars and subscription products may request a refund at (800) 223-8720 or You must do so by April 1, 2019.

Thank you for your business and loyalty over the years. We sincerely apologize for any inconvenience caused.

Best regards,
The ProEdTech Team