Shopping Cart (0) items Sign In

Construction Claims Monthly - Devoted exclusively to the problems of construction contracting since 1963

‹ Prev article: 

Government's "Reverse-delay" Claim Denied Changes-deductive

Thursday, June 09, 2005 03:00 pm

Government's "Reverse-delay" Claim Denied Changes-deductive

The Armed Services Board of Contract Appeals has denied the government's "reverse-delay"claim against a contractor. The government relaxed the contract requirements, but failed to prove a beneficial effect on the schedule's critical path.

The Army Corps of Engineers awarded a contract to Fru-Con Construction Corp. for rehabilitation of a dam on the Ohio River near Gallipolis, West Virginia. The work included extensive painting of the gates.

The contract stated that Fru-Con and its subcontractors could use a set of new maintenance bulkheads while performing [...]

› Next article: 
Sign up now for Construction Claims Monthly Online! Your own virtual help desk of must-have techniques, tutorials, and how-to articles.
Join Now Construction Claims Monthly! Close