Shopping Cart (0) items Sign In

Construction Claims Monthly - Devoted exclusively to the problems of construction contracting since 1963

‹ Prev article: 
 

No Postponement Of Notice-to-proceed Delay-nonexcusable

Saturday, April 09, 2005 02:40 pm

 
No Postponement Of Notice-to-proceed Delay-nonexcusable

The General Services Administration Board of Contract Appeals has upheld a termination for default due to failure to commence work. The contractor had not been entitled to postponement of issuance of the notice-toproceed.

The GSA awarded a contract to NECCO, Inc. to replace the roof of th [...]

 
› Next article: 
 
Sign up now for Construction Claims Monthly Online! Your own virtual help desk of must-have techniques, tutorials, and how-to articles.
 
Join Now Construction Claims Monthly! Close