Shopping Cart (0) items Sign In

Construction Claims Monthly - Devoted exclusively to the problems of construction contracting since 1963

‹ Prev article: 
 

Financial Data Not Consistent With Eichleay Formula Delay-damages; Overhead

Saturday, December 03, 2005 04:41 pm

 
Financial Data Not Consistent With Eichleay Formula Delay-damages; Overhead

The U.S. Court of Federal Claims has ruled that while a contractor had established entitlement to unabsorbed home office overhead, the contractor's financial data did not comport with the proper use of the Eichleay formula.

The Navy awarded a contract to Orlosky, Inc. to replace high voltage circuit breakers and to perform a coordination study of the electrical system at a weapons center on San Nicholas Island off the coast of California. The contract called for completion in 200 calendar days.

Orlosky experienced a series of government-caused delays involving lack of power out [...]

 
› Next article: 
 
Sign up now for Construction Claims Monthly Online! Your own virtual help desk of must-have techniques, tutorials, and how-to articles.
 
Join Now Construction Claims Monthly! Close