Shopping Cart (0) items Sign In

Construction Claims Monthly - Devoted exclusively to the problems of construction contracting since 1963

‹ Prev article: 
 

Board Addresses 9-11 Base Closure Delay-compensable; Site Access

Friday, December 03, 2004 03:20 pm

 
Board Addresses 9-11 Base Closure Delay-compensable; Site Access

The Armed Services Board of Contract Appeals has ruled that denial of site access following the September 11 terrorist attacks would be compensable unless the base closure was "public and general" in nature.

The Army Corps of Engineers awarded a contract to Conner Brothers Construction Co., Inc. to build a headquarters facility for the 75th Ranger Regimental Compound at Fort Benning, Georgia. The Ranger Compound was fenced off within Fort Benning and was a controlled access area. The contract included a standard Sus [...]

 
› Next article: 
 
Sign up now for Construction Claims Monthly Online! Your own virtual help desk of must-have techniques, tutorials, and how-to articles.
 
Join Now Construction Claims Monthly! Close