Shopping Cart (0) items Sign In

Construction Claims Monthly - Devoted exclusively to the problems of construction contracting since 1963

‹ Prev article: 
 

Bonding Capacity Impaired By Other Contracts Delay-damages; Overhead

Tuesday, February 03, 2004 11:57 am

 
Bonding Capacity Impaired By Other Contracts Delay-damages; Overhead

The Armed Services Board of Contract Appeals has ruled that a contractor's inability to take on replacement work during a period of suspended work resulted from circumstances on other contracts. The contractor was not entitled to recover unabsorbed home office overhead.

The Naval Facilities Eng [...]

 
› Next article: 
 
Sign up now for Construction Claims Monthly Online! Your own virtual help desk of must-have techniques, tutorials, and how-to articles.
 
Join Now Construction Claims Monthly! Close