Shopping Cart (0) items Sign In

Construction Claims Monthly - Devoted exclusively to the problems of construction contracting since 1963

‹ Prev article: 
 

Government Failed To Account For Excusable Delay Delay-excusable; Termination-default

Monday, June 02, 2003 02:58 pm

 
Government Failed To Account For Excusable Delay Delay-excusable; Termination-default

The Armed Services Board of Contract Appeals has ruled that the government constructively changed testing requirements without granting an extension of time to account for resulting delay. The government could not default the contractor for late completion.

The Air Force awarded a contract to American Service & Supply, Inc. to furnish and install two new gaspowered air compressors and their engines in the boiler room of a building at Tinker Air Force Base in Oklahoma. The contract called for all components to be mounted on a structural base, or "skid."Each unit w [...]

 
› Next article: 
 
Sign up now for Construction Claims Monthly Online! Your own virtual help desk of must-have techniques, tutorials, and how-to articles.
 
Join Now Construction Claims Monthly! Close